{"id":4936,"date":"2025-06-17T10:22:43","date_gmt":"2025-06-17T10:22:43","guid":{"rendered":"https:\/\/www.legalserviceindia.com\/Legal-Articles\/?p=4936"},"modified":"2025-10-12T11:19:01","modified_gmt":"2025-10-12T11:19:01","slug":"mnre-dispute-resolution-mechanism-2023","status":"publish","type":"post","link":"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/","title":{"rendered":"Revised Dispute Resolution Mechanism in Renewable Energy Sector: A New Framework Introduced by MNRE"},"content":{"rendered":"<p><b>Overview<\/b><\/p><div id=\"ez-toc-container\" class=\"ez-toc-v2_0_82_2 counter-hierarchy ez-toc-counter ez-toc-grey ez-toc-container-direction\">\n<div class=\"ez-toc-title-container\">\n<p class=\"ez-toc-title\" style=\"cursor:inherit\">Table of Contents<\/p>\n<span class=\"ez-toc-title-toggle\"><a href=\"#\" class=\"ez-toc-pull-right ez-toc-btn ez-toc-btn-xs ez-toc-btn-default ez-toc-toggle\" aria-label=\"Toggle Table of Content\"><span class=\"ez-toc-js-icon-con\"><span class=\"\"><span class=\"eztoc-hide\" style=\"display:none;\">Toggle<\/span><span class=\"ez-toc-icon-toggle-span\"><svg style=\"fill: #0c0c0c;color:#0c0c0c\" xmlns=\"http:\/\/www.w3.org\/2000\/svg\" class=\"list-377408\" width=\"20px\" height=\"20px\" viewBox=\"0 0 24 24\" fill=\"none\"><path d=\"M6 6H4v2h2V6zm14 0H8v2h12V6zM4 11h2v2H4v-2zm16 0H8v2h12v-2zM4 16h2v2H4v-2zm16 0H8v2h12v-2z\" fill=\"currentColor\"><\/path><\/svg><svg style=\"fill: #0c0c0c;color:#0c0c0c\" class=\"arrow-unsorted-368013\" xmlns=\"http:\/\/www.w3.org\/2000\/svg\" width=\"10px\" height=\"10px\" viewBox=\"0 0 24 24\" version=\"1.2\" baseProfile=\"tiny\"><path d=\"M18.2 9.3l-6.2-6.3-6.2 6.3c-.2.2-.3.4-.3.7s.1.5.3.7c.2.2.4.3.7.3h11c.3 0 .5-.1.7-.3.2-.2.3-.5.3-.7s-.1-.5-.3-.7zM5.8 14.7l6.2 6.3 6.2-6.3c.2-.2.3-.5.3-.7s-.1-.5-.3-.7c-.2-.2-.4-.3-.7-.3h-11c-.3 0-.5.1-.7.3-.2.2-.3.5-.3.7s.1.5.3.7z\"\/><\/svg><\/span><\/span><\/span><\/a><\/span><\/div>\n<nav><ul class='ez-toc-list ez-toc-list-level-1 ' ><li class='ez-toc-page-1 ez-toc-heading-level-2'><a class=\"ez-toc-link ez-toc-heading-1\" href=\"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/#Context_and_Evolution_of_the_DRM\" >Context and Evolution of the DRM<\/a><\/li><li class='ez-toc-page-1 ez-toc-heading-level-2'><a class=\"ez-toc-link ez-toc-heading-2\" href=\"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/#Constitution_of_the_Dispute_Resolution_Committee_DRC\" >Constitution of the Dispute Resolution Committee (DRC)<\/a><\/li><li class='ez-toc-page-1 ez-toc-heading-level-2'><a class=\"ez-toc-link ez-toc-heading-3\" href=\"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/#Scope_and_Applicability_of_the_Mechanism\" >Scope and Applicability of the Mechanism<\/a><\/li><li class='ez-toc-page-1 ez-toc-heading-level-2'><a class=\"ez-toc-link ez-toc-heading-4\" href=\"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/#Dispute_Resolution_Procedure\" >Dispute Resolution Procedure<\/a><\/li><li class='ez-toc-page-1 ez-toc-heading-level-2'><a class=\"ez-toc-link ez-toc-heading-5\" href=\"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/#Timelines_for_Specific_Disputes\" >Timelines for Specific Disputes:<\/a><ul class='ez-toc-list-level-3' ><li class='ez-toc-heading-level-3'><a class=\"ez-toc-link ez-toc-heading-6\" href=\"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/#a_Extension_of_Time_EoT_due_to_Force_Majeure_or_Contractual_Terms\" >a. Extension of Time (EoT) due to Force Majeure or Contractual Terms:<\/a><\/li><li class='ez-toc-page-1 ez-toc-heading-level-3'><a class=\"ez-toc-link ez-toc-heading-7\" href=\"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/#b_EoT_Outside_Contractual_Terms_Other_Disputes\" >b. EoT Outside Contractual Terms &amp; Other Disputes:<\/a><\/li><\/ul><\/li><li class='ez-toc-page-1 ez-toc-heading-level-2'><a class=\"ez-toc-link ez-toc-heading-8\" href=\"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/#Application_Fees_and_Review_Process\" >Application Fees and Review Process:<\/a><\/li><li class='ez-toc-page-1 ez-toc-heading-level-2'><a class=\"ez-toc-link ez-toc-heading-9\" href=\"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/#Remuneration_and_Financial_Provisions\" >Remuneration and Financial Provisions<\/a><\/li><li class='ez-toc-page-1 ez-toc-heading-level-2'><a class=\"ez-toc-link ez-toc-heading-10\" href=\"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/#Operational_Challenges_and_Legal_Concerns\" >Operational Challenges and Legal Concerns<\/a><\/li><li class='ez-toc-page-1 ez-toc-heading-level-2'><a class=\"ez-toc-link ez-toc-heading-11\" href=\"https:\/\/www.legalserviceindia.com\/Legal-Articles\/mnre-dispute-resolution-mechanism-2023\/#Assessment_and_Way_Forward\" >Assessment and Way Forward<\/a><\/li><\/ul><\/nav><\/div>\n\n<p>The Ministry of New &amp; Renewable Energy (MNRE) released a new directive on June 7, 2023, to restructure the dispute resolution framework governing conflicts between Renewable Energy (RE) Power Developers or EPC Contractors and the Renewable Energy Implementing Agencies (REIAs). This revamped mechanism aims to ensure a more timely, transparent, and impartial resolution process within the renewable energy domain.<\/p>\n<h2><span class=\"ez-toc-section\" id=\"Context_and_Evolution_of_the_DRM\"><\/span>Context and Evolution of the DRM<span class=\"ez-toc-section-end\"><\/span><\/h2>\n<p>This Order replaces the previous mechanism instituted via the MNRE Order dated June 18, 2019, and its subsequent amendments. The newly introduced guidelines establish an upgraded Dispute Resolution Mechanism (DRM) tailored to meet the evolving needs of the sector.<\/p>\n<h2><span class=\"ez-toc-section\" id=\"Constitution_of_the_Dispute_Resolution_Committee_DRC\"><\/span>Constitution of the Dispute Resolution Committee (DRC)<span class=\"ez-toc-section-end\"><\/span><\/h2>\n<p>A central feature of the new DRM is the formation of a Dispute Resolution Committee (DRC). This body is designed to independently address disputes arising between RE Power Developers\/EPC Contractors and REIAs such as SECI, NTPC, NHPC, SJVN, and others designated by MNRE. The DRC will comprise three members with high ethical standards, all based in Delhi-NCR, and each not exceeding 70 years of age.<\/p>\n<h2><span class=\"ez-toc-section\" id=\"Scope_and_Applicability_of_the_Mechanism\"><\/span>Scope and Applicability of the Mechanism<span class=\"ez-toc-section-end\"><\/span><\/h2>\n<p>The DRM covers all schemes and projects implemented by REIAs. It governs contracts between REIAs and EPC Contractors related to RE projects owned by REIAs, with a prerequisite that REIAs agree to comply with outcomes determined under this mechanism.<\/p>\n<p>Disputes eligible under the DRM include:<\/p>\n<ul>\n<li>Time extensions due to force majeure events or covered by contract<\/li>\n<li>Time extensions not defined in contract terms<\/li>\n<li>All other disputes not related to tariff regulation<\/li>\n<\/ul>\n<p>However, tariff disputes and change in law claims remain under the jurisdiction of Electricity Regulatory Commissions (ERCs).<\/p>\n<h2><span class=\"ez-toc-section\" id=\"Dispute_Resolution_Procedure\"><\/span>Dispute Resolution Procedure<span class=\"ez-toc-section-end\"><\/span><\/h2>\n<p><strong>Initial Application to REIA:<\/strong> The disputing party must first approach the relevant REIA, which must provide a reasoned (speaking) order, even if the issue falls outside the existing contractual terms.<\/p>\n<p><strong>Appeal to DRC:<\/strong> If unsatisfied with the REIA&#8217;s decision, an appeal may be filed with the DRC within 21 days.<\/p>\n<h2><span class=\"ez-toc-section\" id=\"Timelines_for_Specific_Disputes\"><\/span>Timelines for Specific Disputes:<span class=\"ez-toc-section-end\"><\/span><\/h2>\n<h3><span class=\"ez-toc-section\" id=\"a_Extension_of_Time_EoT_due_to_Force_Majeure_or_Contractual_Terms\"><\/span>a. Extension of Time (EoT) due to Force Majeure or Contractual Terms:<span class=\"ez-toc-section-end\"><\/span><\/h3>\n<ul>\n<li>Request must be made within the contractually prescribed period, or within 7 days if no timeframe is defined.<\/li>\n<li>REIA must respond within 21 days.<\/li>\n<li>If dissatisfied, the contractor\/developer can appeal to the DRC within 21 days.<\/li>\n<\/ul>\n<h3><span class=\"ez-toc-section\" id=\"b_EoT_Outside_Contractual_Terms_Other_Disputes\"><\/span>b. EoT Outside Contractual Terms &amp; Other Disputes:<span class=\"ez-toc-section-end\"><\/span><\/h3>\n<ul>\n<li>Issues like delay in land allotment or regulatory clearances must be raised within 7 days.<\/li>\n<li>REIA\u2019s decision must be given within 21 days.<\/li>\n<li>Appeals must be filed within 21 days if dissatisfied.<\/li>\n<li>Overlapping claims cannot result in multiple EoT extensions.<\/li>\n<\/ul>\n<h2><span class=\"ez-toc-section\" id=\"Application_Fees_and_Review_Process\"><\/span>Application Fees and Review Process:<span class=\"ez-toc-section-end\"><\/span><\/h2>\n<ul>\n<li>Applications to the DRC must include a fee, the amount of which depends on the dispute type.<\/li>\n<li>DRC will submit its recommendations to MNRE within 21 days.<\/li>\n<li>MNRE, after consulting its finance division (IFD), will place the recommendations before the Hon&#8217;ble Minister of New &amp; Renewable Energy for a final decision within another 21 days.<\/li>\n<li>Importantly, no coercive steps will be taken on matters under DRC review until final resolution.<\/li>\n<\/ul>\n<h2><span class=\"ez-toc-section\" id=\"Remuneration_and_Financial_Provisions\"><\/span>Remuneration and Financial Provisions<span class=\"ez-toc-section-end\"><\/span><\/h2>\n<ul>\n<li>Each DRC member will receive a monthly honorarium of INR 1,00,000 and INR 20,000 per sitting (maximum of five sittings).<\/li>\n<li>These costs are covered primarily through collected application fees, with REIAs sharing the burden if fees are insufficient.<\/li>\n<\/ul>\n<h2><span class=\"ez-toc-section\" id=\"Operational_Challenges_and_Legal_Concerns\"><\/span>Operational Challenges and Legal Concerns<span class=\"ez-toc-section-end\"><\/span><\/h2>\n<p>A key concern is the dependency of REIAs on Distribution Companies (DISCOMs) with whom they have back-to-back contractual obligations. This raises doubts about whether REIAs can unilaterally agree to developer requests if DISCOMs are non-compliant. Additionally, the binding nature of DRC decisions on DISCOMs remains unclear.<\/p>\n<p>Further ambiguity exists on the legal consequences if a developer\u2019s claim is rejected by the DRC. It is uncertain whether they can then proceed to ERCs or arbitration, as per their contract. There is also apprehension that an adverse DRC ruling may affect subsequent legal or arbitral proceedings.<\/p>\n<h2><span class=\"ez-toc-section\" id=\"Assessment_and_Way_Forward\"><\/span>Assessment and Way Forward<span class=\"ez-toc-section-end\"><\/span><\/h2>\n<p>The revised DRM presents a step forward with its structured timelines, multi-tiered review, and emphasis on neutrality. However, its real-world impact remains to be seen. The multi-layered process involving the DRC, MNRE, and the Minister could delay final resolutions despite intentions for speedy disposal.<\/p>\n<p>To ensure success, there must be strict adherence to timelines, institutional cooperation, and legal clarity on how DRC decisions interact with other forums like ERCs and arbitration. The efficient functioning and credibility of the DRC will be vital in establishing trust in this new system.<\/p>\n<p>Continued observation of its implementation will reveal whether the mechanism genuinely facilitates faster and fairer dispute resolution in India\u2019s rapidly expanding renewable energy sector.<\/p>\n","protected":false},"excerpt":{"rendered":"<p>Overview The Ministry of New &amp; Renewable Energy (MNRE) released a new directive on June 7, 2023, to restructure the dispute resolution framework governing conflicts between Renewable Energy (RE) Power Developers or EPC Contractors and the Renewable Energy Implementing Agencies (REIAs). This revamped mechanism aims to ensure a more timely, transparent, and impartial resolution process<\/p>\n","protected":false},"author":55,"featured_media":0,"comment_status":"open","ping_status":"open","sticky":false,"template":"","format":"standard","meta":{"_bbp_topic_count":0,"_bbp_reply_count":0,"_bbp_total_topic_count":0,"_bbp_total_reply_count":0,"_bbp_voice_count":0,"_bbp_anonymous_reply_count":0,"_bbp_topic_count_hidden":0,"_bbp_reply_count_hidden":0,"_bbp_forum_subforum_count":0,"two_page_speed":[],"_jetpack_memberships_contains_paid_content":false,"_joinchat":[],"footnotes":""},"categories":[19],"tags":[],"class_list":{"0":"post-4936","1":"post","2":"type-post","3":"status-publish","4":"format-standard","6":"category-civil-law"},"jetpack_featured_media_url":"","jetpack_sharing_enabled":true,"_links":{"self":[{"href":"https:\/\/www.legalserviceindia.com\/Legal-Articles\/wp-json\/wp\/v2\/posts\/4936","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.legalserviceindia.com\/Legal-Articles\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.legalserviceindia.com\/Legal-Articles\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.legalserviceindia.com\/Legal-Articles\/wp-json\/wp\/v2\/users\/55"}],"replies":[{"embeddable":true,"href":"https:\/\/www.legalserviceindia.com\/Legal-Articles\/wp-json\/wp\/v2\/comments?post=4936"}],"version-history":[{"count":0,"href":"https:\/\/www.legalserviceindia.com\/Legal-Articles\/wp-json\/wp\/v2\/posts\/4936\/revisions"}],"wp:attachment":[{"href":"https:\/\/www.legalserviceindia.com\/Legal-Articles\/wp-json\/wp\/v2\/media?parent=4936"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.legalserviceindia.com\/Legal-Articles\/wp-json\/wp\/v2\/categories?post=4936"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.legalserviceindia.com\/Legal-Articles\/wp-json\/wp\/v2\/tags?post=4936"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}